Last Updated: 18/05/2026

Welcome to DARSHIL GREEN ENERGY PRIVATE LIMITED. These Terms & Conditions govern your access to and use of our website, products, and services related to solar energy systems, electrical equipment, EV charging solutions, and associated services.

By accessing our website, placing an order, requesting a quotation, or using our services, you agree to comply with these Terms & Conditions.

1. Acceptance of Terms

By using this website, you confirm that:

  • You have read, understood, and agreed to these Terms & Conditions
  • You are at least 18 years of age
  • You will comply with all applicable laws and regulations
  • All information provided by you is accurate and complete

If you do not agree with these Terms, please discontinue the use of our website and services.

2. Scope of Products & Services

DARSHIL GREEN ENERGY PRIVATE LIMITED deals in products and services including but not limited to:

  • Solar Panels
  • Solar Inverters & UPS Systems
  • Solar Batteries & Energy Storage Solutions
  • Solar Charge Controllers
  • Solar Water Heaters
  • Solar Water Pumps
  • LT/HT Electrical Panels & Switchgears
  • MS Frames & Solar Mounting Structures
  • EV Charging Stations & Accessories
  • Solar Installation, EPC & Maintenance Services

Availability of products and services may vary depending on location, stock, technical feasibility, and project requirements.

3. Use of the Website

You agree not to:

  • Use the website for unlawful, fraudulent, or harmful activities
  • Copy, reproduce, distribute, or modify website content without written permission
  • Attempt to gain unauthorized access to systems or data
  • Introduce malware, viruses, or harmful code
  • Disrupt or interfere with website functionality or security
  • Use our content, product listings, or branding for unauthorized commercial purposes

Violation of these conditions may result in legal action or termination of access.

4. Product Information & Technical Specifications

We strive to provide accurate product descriptions, specifications, pricing, and compatibility information. However:

  • Product appearance, color, or design may vary slightly from images shown
  • Technical specifications may change without prior notice
  • Product performance may vary depending on installation conditions and usage
  • Minor typographical or pricing errors may occur

We reserve the right to correct any errors or update information without prior notice.

5. Quotations & Pricing

All quotations provided for products, EPC projects, installations, and maintenance services are subject to:

  • Site inspection (where applicable)
  • Product availability
  • Applicable taxes and government regulations
  • Transportation and installation charges

Prices may change without prior notice due to market fluctuations, raw material costs, or manufacturer pricing updates.

6. Orders & Payments

By placing an order, you confirm that:

  • The information provided is accurate and complete
  • You are authorized to use the selected payment method
  • You agree to pay all applicable charges, taxes, and fees

We reserve the right to:

  • Reject or cancel orders due to pricing errors, stock unavailability, or suspected fraud
  • Request additional verification before processing orders
  • Limit quantities or restrict purchases in certain situations

Orders will be confirmed only after successful payment verification and acceptance by the Company.

7. Shipping, Delivery & Installation

  • Delivery timelines are approximate and may vary by location
  • Delays may occur due to logistics, weather conditions, supplier delays, or other external factors
  • Customers are responsible for providing accurate delivery and installation details
  • Installation schedules depend on technical feasibility, weather conditions, and site readiness

The Company is not liable for delays caused by third-party courier or logistics providers.

8. Installation & EPC Services

For solar installation and EPC projects:

  • Customers must provide safe and lawful site access
  • Necessary government approvals, permissions, or subsidies (if applicable) remain the customer’s responsibility unless specifically agreed otherwise
  • Installation timelines may vary depending on project complexity and environmental conditions
  • Performance estimates are indicative and may vary based on sunlight, shading, usage patterns, and maintenance

9. Returns, Refunds & Replacements

All returns, refunds, cancellations, and replacements are governed by our separate Refund & Return Policy.

Customers are advised to review the policy before placing any order.

10. Warranty

Certain products may carry manufacturer warranties subject to brand-specific terms and conditions.

  • Warranty coverage varies by product category and manufacturer
  • Physical damage, misuse, unauthorized repairs, or improper installation may void warranties
  • Warranty claims may require inspection by authorized service providers

The Company is not responsible for manufacturer warranty decisions.

11. Customer Responsibilities

Customers agree to:

  • Use products according to safety instructions and applicable regulations
  • Ensure proper electrical infrastructure and installation conditions
  • Perform regular maintenance where required
  • Avoid misuse, tampering, or unauthorized modifications of products

The Company shall not be liable for damages resulting from improper usage or installation by unauthorized personnel.

12. Account Responsibilities

If you create an account on our website:

  • You are responsible for maintaining confidentiality of login credentials
  • All activities conducted under your account remain your responsibility
  • You must notify us immediately in case of unauthorized access or security breaches

We reserve the right to suspend accounts involved in suspicious or fraudulent activities.

13. Limitation of Liability

To the maximum extent permitted by law, DARSHIL GREEN ENERGY PRIVATE LIMITED shall not be liable for:

  • Indirect, incidental, or consequential damages
  • Loss of profits, revenue, or business opportunities
  • Delays caused by third-party services
  • Damages arising from improper installation or misuse
  • Performance variations due to environmental or site conditions

Our total liability shall not exceed the amount paid by the customer for the specific product or service.

14. Third-Party Links & Services

Our website may contain links to third-party websites, payment gateways, or external services.

We are not responsible for:

  • Third-party content
  • Privacy practices
  • Transactions or disputes arising from external websites

Users access third-party services at their own risk.

15. Intellectual Property

All website content including:

  • Logos
  • Product images
  • Text content
  • Product descriptions
  • Graphics
  • Website design and layout

are the intellectual property of DARSHIL GREEN ENERGY PRIVATE LIMITED unless otherwise stated.

Unauthorized use, reproduction, or distribution is strictly prohibited.

16. Indemnification

You agree to indemnify and hold harmless DARSHIL GREEN ENERGY PRIVATE LIMITED, its directors, employees, and affiliates from any claims, liabilities, damages, or expenses arising from:

  • Violation of these Terms
  • Misuse of the website or products
  • Violation of applicable laws
  • Infringement of third-party rights

17. Force Majeure

We shall not be held responsible for delays or failure in performance due to circumstances beyond our reasonable control, including but not limited to:

  • Natural disasters
  • Floods, fires, or earthquakes
  • Government restrictions
  • Strikes or labor disputes
  • Supply chain disruptions
  • Internet or technical failures
  • Pandemic-related disruptions

18. Termination of Access

We reserve the right to suspend or terminate access to our website or services if:

  • These Terms are violated
  • Fraudulent or suspicious activity is detected
  • Website misuse or security threats occur

Termination may occur without prior notice.

19. Governing Law & Jurisdiction

These Terms & Conditions shall be governed by and interpreted in accordance with the laws of India.

Any disputes arising from these Terms shall fall under the exclusive jurisdiction of the courts located in Gurugram, Haryana.

20. Changes to Terms & Conditions

We may revise or update these Terms & Conditions at any time without prior notice.

Continued use of the website after changes are posted constitutes acceptance of the updated Terms.

21. Contact Us

For any questions, support requests, or concerns regarding these Terms & Conditions, please contact:

DARSHIL GREEN ENERGY PRIVATE LIMITED
Address: 5th Floor, Unit No. 565D, Spaze I Tech Park, Tower-B1, Sector 49, Gurugram, Haryana, 122103
Email: info@darshilgreenenergy.com
Phone: +91 8796044729